Transcription
Contract # 36514Amendment # 2STATE OF VERMONTCONTRACT AMENDMENTIt is hereby agreed by and between the State of Vermont, Department of Buildings and GeneralServices (the "State") and MSK Engineering & Design, with a principal place of business inBennington, Vermont (the "Contractor") that the contract between them originally dated as ofJune 18th, 2018, Contract # 36514, as amended to date, (the “Contract”) is hereby amended asfollows:I.Contract Term. The Contract end date, wherever such reference appears in theContract, shall be changed from 06/18/2021 to 06/18/2022.II.Attachment A, Scope of Services. The scope of services is amended to include thefollowing:Section 4 of Attachment A is added by the addition of the following requirements.4. Entities Authorized to Use This Agreement. This Contract may be used by (a) all departments,offices, institutions, and other agencies of the State of Vermont and counties (each a “StatePurchaser”) according to the process for ordering and other restrictions applicable to StatePurchasers set forth herein; and (b) political subdivisions of the State of Vermont and anyinstitution of higher education chartered in Vermont and accredited or holding a certificate ofapproval from the State Board of Education as authorized under 29 V.S.A. § 902 (each an“Additional Purchaser”). State Purchasers and Additional Purchasers are also referred to herein asa “Purchasing Entity” or “Purchasing Entities”. Issues concerning eligibility to purchase underthis Agreement are solely within the authority of the State of Vermont Chief ProcurementOfficer. The State of Vermont and its officers and employees shall have no responsibility orliability for Additional Purchasers. Each Additional Purchaser is to make its own determinationwhether this Contract is consistent with its procurement policies and regulations.Taxes Due to the State. Contractor certifies under the pains and penalties of perjury that, as ofthe date this contract amendment is signed, the Contractor is in good standing with respect to, orin full compliance with a plan to pay, any and all taxes due the State of Vermont.Child Support (Applicable to natural persons only; not applicable to corporations, partnerships orLLCs). Contractor is under no obligation to pay child support or is in good standing with respectto or in full compliance with a plan to pay any and all child support payable under a supportorder as of the date of this amendment.Certification Regarding Suspension or Debarment. Contractor certifies under the pains andpenalties of perjury that, as of the date this contract amendment is signed, neither Contractor norContractor’s principals (officers, directors, owners, or partners) are presently debarred,suspended, proposed for debarment, declared ineligible or excluded from participation in federalprograms, or programs supported in whole or in part by federal funds.Revision Date: 02/02/2019
Contract # 36514Amendment # 2Contractor further certifies under pains and penalties of perjury that, as of the date this contractamendment is signed, Contractor is not presently debarred, suspended, nor named on the State’sdebarment list at: rmentThis document consists of 2 pages. Except as modified by this Amendment No. 2, all provisionsof the Contract remain in full force and effect.The signatures of the undersigned indicate that each has read and agrees to be bound by thisAmendment to the Contract.STATE OF VERMONTMSK Engineering & DesignBy:By:Name:Jennifer Fitch - CommissionerName:Buildings & General ServicesTitle:Title:Date:Date:Revision Date: 02/02/2019
Contract #36514Amendment #1STATE OF VERMONTCONTRACT AMENDMENTIt is hereby agreed by and between the State of Vermont, Department of Buildings & GeneralServices (the "State") and MSK Engineering & Design with a principal place of business inBennington, VT (the "Contractor") that the contract between them originally dated as of June 18,2018, Contract # 36514, as amended to date, (the “Contract”) is hereby amended as follows:I.Contract Term. The Contract end date, wherever such reference appears in theContract, shall be changed from June 18, 2020 to June 18, 2021. The Contract Term maybe renewed for one additional one-year period at the discretion of the State.Taxes Due to the State. Contractor certifies under the pains and penalties of perjury that, as ofthe date this contract amendment is signed, the Contractor is in good standing with respect to, orin full compliance with a plan to pay, any and all taxes due the State of Vermont.Child Support (Applicable to natural persons only; not applicable to corporations, partnerships orLLCs). Contractor is under no obligation to pay child support or is in good standing with respectto or in full compliance with a plan to pay any and all child support payable under a supportorder as of the date of this amendment.Certification Regarding Suspension or Debarment. Contractor certifies under the pains andpenalties of perjury that, as of the date this contract amendment is signed, neither Contractor norContractor’s principals (officers, directors, owners, or partners) are presently debarred,suspended, proposed for debarment, declared ineligible or excluded from participation in federalprograms, or programs supported in whole or in part by federal funds.Contractor further certifies under pains and penalties of perjury that, as of the date this contractamendment is signed, Contractor is not presently debarred, suspended, nor named on the State’sdebarment list at: rmentThis document consists of 2 pages. Except as modified by this Amendment No. 1, all provisionsof the Contract remain in full force and effect.[Remainder of Page Intentionally Left Blank]1Revision Date: 12/12/2018
Contract #36514Amendment #1The signatures of the undersigned indicate that each has read and agrees to be bound by thisAmendment to the Contract.STATE OF VERMONTMSK ENGINEERING & DESIGNBy:By:Name: ChristopherColeName:Title:Commissioner - Buildings & General Services Title:Date:Date:2Revision Date: 12/12/2018
CONTRACT 36514MASTER COPY DISTRIBUTED(Contractor, Accounting, Regional Director, Project Manager, DFM)DEPARTMENT OF BUILDINGS AND GENERAL SERVICES(Revised 03/2018)THE STATE OF VERMONTSTANDARD FORM OF AGREEMENT BETWEENSTATE OF VERMONT OR ANY AGENCYTHEREOF AND ARCHITECT/ENGINEERAGREEMENTmade this 18th day of June in the year 2018.BETWEENAgency of AdministrationDepartment of Buildings and General ServicesTwo Governor Aiken AvenueMontpelier, Vermont 05633-5801the State.MS&K, Inc.PO Box 139Bennington, Vermont 05201the ARCHITECT/ENGINEER.It is the intention of the State to utilize architectural and engineering services on a as needed basis.The State and the ARCHITECT/ENGINEER agree as set forth below:The period of performance under this contract shall commence on June 18th, 2018 and end on June 18th, 2020 with anoption to renew for two additional one-year terms.MAXIMUM LIMITING AMOUNT 400,000.00PROJECT DESCRIPTION:This contract may be utilized for design of new construction and renovation projects, including any and all phases fromfeasibility/programming through construction administration; including but not limited to code analysis, studies,permitting, CAD drafting, surveying, and construction estimating, as required for the specific project. Projects are notto exceed 50,000.00, including all costs associated with the individual project, such as labor, material, equipment, etc.
CONTRACT 365141.The ARCHITECT/ENGINEER shall provide professional services for the Project in accordance with the Terms and Conditionsof this Agreement.A. The ARCHITECT/ENGINEER shall provide the professional services for the Project utilizing his/ her requisite skills,ability, and judgment reasonably and without neglect. Specifically, the ARCHITECT/ENGINEER shall: (1) be licensedby the State of Vermont as an ARCHITECT/ENGINEER; and (2) design the Project in compliance with all federal,state and local building codes in effect at the time including any and all permit conditions that may be imposed byauthorities having jurisdiction.B.For purposes of this Agreement, the ARCHITECT/ENGINEER shall be licensed in Vermont before executing thiscontract and shall maintain his/her license for the duration of this project.TERMS AND CONDITIONS OF AGREEMENT BETWEEN STATE AND ARCHITECT/ENGINEERARTICLE 1 - ARCHITECT/ENGINEER'S SERVICES1.1.BASIC SERVICES: INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE1.1.1.The ARCHITECT/ENGINEER'S Basic Services consist of the phases described below. Except as specificallyprovided for herein, the ARCHITECT/ENGINEER shall provide to the State all landscaping architectural servicesas well as civil, structural, mechanical and electrical engineering in connection with the Project.1.1.2.The ARCHITECT/ENGINEER shall ensure the project complies with all applicable codes and guidelines in effectat the time of the design, including but not limited to:1.1.2.1.Vermont Fire and Safety Building Code available online at http://firesafety.vermont.gov1.1.2.2.Vermont Commercial Building Energy Standardshttp://publicservice.vermont.gov/energy efficiency/cbes1.1.2.3.The ARCHITECT/ENGINEER, as directed by the State, will be required to integrate State of VermontDepartment of Buildings and General Services’ Design Guidelines into the development of thedesign for this project. The latest version is available online en reports delivered under the terms of this contract shall be printed using both sides of the paper.1.1.4.PROGRAMMING PHASE: INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOTAPPLICABLE1.1.5.April 22, 20181.1.4.1.The ARCHITECT shall consult with the Owner, together with building occupants and Agencyadministration, to develop a comprehensive space program for the project. The ARCHITECT shalladvise best practices for each specialty as well as the common areas. The program should becomplete and detailed, including equipment (fixed and movable) and furnishings throughout thebuilding.1.1.4.2.The ARCHITECT shall consult with the Owner and Efficiency Vermont to establish the Basis ofDesign, based on BGS Design Guidelines, BGS Space Management Guidelines, LEED manuals,ASHRAE 90.1, Vermont Commercial Building Energy Standard, ASHRAE Advanced Energy DesignGuide for Small to Medium Office Buildings, and other guides that are identified for the use of thebuilding.SCHEMATIC DESIGN PHASE: INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOTAPPLICABLEPage 2 of 16
CONTRACT 365141.1.6.1.1.7.April 22, 20181.1.5.1.The ARCHITECT/ENGINEER shall consult with the State to ascertain the requirements of the Project,and the ARCHITECT/ENGINEER and the State shall confirm such requirements in writing.1.1.5.2.The ARCHITECT/ENGINEER shall prepare Schematic Design Studies consisting of drawings and otherdocuments illustrating the scale and relationship of Project components for and until approved bythe State.1.1.5.3.The ARCHITECT/ENGINEER shall conduct meetings with the State, Efficiency Vermont, and relevantmembers of the design team, to review the Project and elicit ideas for consideration in developingthe most energy efficient project supportable by funding opportunities and consistent withprogram intent.1.1.5.4.The ARCHITECT/ENGINEER shall prepare for the State an initial accounting of how the Project mayrespond to LEED criteria considering available opportunities.1.1.5.5.The ARCHITECT/ENGINEER shall submit to the State a Statement of Probable Construction Costbased on current area, volume or other unit costs for and until approved by the State.DESIGN DEVELOPMENT PHASE: INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOTAPPLICABLE1.1.6.1.The ARCHITECT/ENGINEER shall prepare from the approved Schematic Design Studies, the DesignDevelopment Documents consisting of drawings (including at least architectural, landscaping, civil,structural, mechanical and electrical plans, building sections; and finish schedule), outlinespecifications following the Construction Specification Institute "CSI" Format and other necessarydocuments to fix and describe the size and character of the entire Project as to its site, structural,mechanical, and electrical systems, materials and other such essentials as may be appropriate, forand until approved by the State.1.1.6.2.The ARCHITECT/ENGINEER shall conduct meetings with the State, Efficiency Vermont, and relevantmembers of the design team, to review the Design Development Documents for the purposes offurthering the energy efficiency objectives of the Project.1.1.6.3.The ARCHITECT/ENGINEER shall prepare for the State a revised accounting of how the Project isresponding to LEED criteria.1.1.6.4.The ARCHITECT/ENGINEER shall submit to the State a revised Statement of Probable ConstructionCost based thereon for and until approved by the State.CONSTRUCTION DOCUMENTS PHASE: INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION ISNOT APPLICABLE1.1.7.1.The ARCHITECT/ENGINEER shall prepare from the approved Design Development Documents, theContract Documents consisting of the working drawings and specifications (following the CSIFormat) setting forth in detail the requirements for the construction of the entire Project, and allnecessary bidding information; and shall assist in the preparation of bidding forms, the Conditionsof the Contract, and the form of the Agreement between the State and the Contractor, for and untilapproved by the State.1.1.7.2.The ARCHITECT/ENGINEER shall prepare for the State a revised accounting of how the Projectresponds to LEED criteria.1.1.7.3.The ARCHITECT/ENGINEER shall submit to the State in writing a Revised Statement of ProbableConstruction Cost based thereon, indicated by changes in requirements or general marketconditions for and until approved by the State.1.1.7.4.The ARCHITECT/ENGINEER shall assist the State as requested in filing the required documents forthe approval of governmental authorities having jurisdiction over the Project.Page 3 of 16
CONTRACT 365141.1.8.1.1.7.5.The ARCHITECT/ENGINEER shall submit the bid set, at 90% completion of the constructiondocuments, to Efficiency Vermont for construction document review.1.1.7.6.The ARCHITECT/ENGINEER shall prepare and submit a complete set of contract bid documents;drawings to be stamped and signed in PDF format, and an unstamped set in DWG format, with acomplete set of specifications in Microsoft Word, to the State at no additional cost.ARCHITECT/ENGINEER shall submit all DWGs documents to the State in AutoCAD 2004 format ornewer with all items embedded including Xrefs and photos. ARCHITECT/ENGINEER shall verifycompatibility with the State’s CADD unit prior to using any AutoCAD specialty software suite orproduct (civil, mechanical, map, etc.). ARCHITECT/ENGINEER shall furnish all custom support CADfiles (fonts, line types, plot styles, etc.) to the State. All drawings shall include a configured layouttab with sheet border and viewports for printing. ARCHITECT/ENGINEER shall submit all electronicfiles to the State on an optical disc, CD, DVD or USB storage drive in a format suitable for use by theDepartment of Buildings and General Services. These documents are to be provided byARCHITECT/ENGINEER at no additional cost to the State.BIDDING OR NEGOTIATION PHASE: INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOTAPPLICABLE1.1.8.1.1.1.9.April 22, 2018The ARCHITECT/ENGINEER, following the State's approval of the Construction Documents and ofthe latest Statement of Probable Construction Cost, shall provide the State with any documents,assistance, or revised construction documents necessary for the State to: obtain bids or negotiatedproposals; and award and prepare construction contracts.CONSTRUCTION PHASE – ADMINISTRATION OF THE CONSTRUCTION CONTRACT: INDICATE IN STATEMENT OFWORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE1.1.9.1.The Construction Phase will commence with the award of the Construction Contract to a selectedvendor (“Contractor”) and will terminate when final payment is made by the State to theContractor. In any event, the construction phase will not extend 60 days beyond the substantialcompletion date unless extended by change order. If such extension occurs, additional costs due tothe ARCHITECT/ENGINEER shall be negotiated with the State.1.1.9.2.The ARCHITECT/ENGINEER shall work with the State during the construction of the Project toprovide the administration of the contract between the State and the Contractor in accordancewith the terms herein and consistent with the contract between the State and the Contractor, andthe extent of his/her duties and responsibilities and the limitations of his/her authority as assignedtherein shall not be modified without his/her written consent.1.1.9.3.The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructionsto the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by theState.1.1.9.4.The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparationor progress.1.1.9.5.The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shallmake such further visits when reasonably requested by the State, as to familiarize himself/herselfwith the progress and quality of the work performed and as to determine, on the basis of suchvisits, if such progress and quality are in accordance with the Contract Documents. TheARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, theARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such timesas in the exercise of his/her professional judgment such findings are appropriate and at leastmonthly, at the conference provided for in Section 1.1.9.6, and further at such times as the Statemay reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive orcontinuous on-site inspections, except as required in the exercise of his/her professional judgmentfor said reports and, except in particular, to fulfill the commissioning requirements. ThePage 4 of 16
CONTRACT 36514ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques,sequences or procedures or for safety precautions and programs in connection with the work, andhe/she shall not be responsible for the Contractor's failure to carry out the work in accordance withthe Contract Documents except as provided for herein specifically between the State and theARCHITECT/ENGINEER.1.1.9.6.In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes subconsultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural,Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of theARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as1.1.9.5, it shall include those sub-consultants when work is being performed in their area ofexpertise. For example, the Mechanical Engineer would inspect the under slab plumbing before itis backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanicalsystems are being installed. The sub-consultant shall also be required to periodically inspect theprogress of the “As-builts” and verify that they are up-to-date and verify such to theARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for thatpay period.1.1.9.7.Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement andupon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month,after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER,determine the amount then owing to the Contractor and shall then issue a certificate of paymentfor the amount agreed upon. The issuance of a Certificate for Payment shall constitute arepresentation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'Sdetermination and report and the data supplied to him/her by the Contractor (without affectinghis/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; thatthe quality of the work is in accordance with the Contract Documents (subject to the results of anyspecified subsequent tests required by the Contract Documents, to immaterial and insubstantialdeviations from the Contract Documents, which will be corrected prior to completion, and to anyfurther specific qualifications stated in the Certificate for Payment); and that the Contractor isentitled to such payment in the amount certified. Provided, however, the issuance of suchcertificate will not affect any obligations of the Contractor to the State. By issuing a certificate forpayment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made anyexamination to ascertain how and for what purpose the Contractor has used the monies paid onaccount of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalfof the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a rightreserved solely to the State.1.1.9.8.The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of allConstruction Documents, and shall have all requisite authority relating thereto for the purposes ofauthorizing the Contractor to proceed or stop with any component of the project after consultationand agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for anyloss or cost incurred by the State arising from delays in the construction schedule caused by anydecision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgmenteither to exercise or not to exercise his/her authority to stop the Work.1.1.9.9.The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and othersubmissions of the Contractor as in conformance with the design concept and information in theContract Documents and the designs and plans relating to the project until approved or notrequiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log atconstruction meetings and report to the State, on a monthly basis, their findings thereon.1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State'sapproval.1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of SubstantialCompletion and Final Completion and shall receive written guarantees and related documentsassembled by the Contractors and shall issue a final certificate of payment in accordance withSection 1.1.9.6.April 22, 2018Page 5 of 16
CONTRACT 365141.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with theBGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGSwebsite http://bgs.vermont.gov/facilities/forms . The ARCHITECT/ENGINEER shall inspect, anddocument, each and every system to ensure that it complies with design intent, including but notlimited to: system installation, system operation, and seasonal changeover.1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not beresponsible to the State for the acts or omissions of the Contractor or any of the Contractor’sagents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEERperforming work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall paythe amount of any increase in the total Contract Price or the total Change Order(s) Price, whichincrease results from an error, inconsistency, or omission in the Contract Documents orinstructions.1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings andspecifications showing all the changes to the Construction Documents made by Addenda, ChangeOrders, Shop Drawings, RFIs and other information received from the Clerk; and GeneralContractor’s As-built markups. The changes to the drawings are to be created on a separate layerin the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are alsoto differentiate the changes made by highlighting in a box, cloud, etc. and be provided in MicrosoftWord. These drawings and specifications shall be supplied within three (3) months of the date ofSubstantial Completion and before final payment.1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warrantyinspection of the completed construction project between the eleventh and twelfth month fromthe date of substantial completion and shall issue a list of defective items needing correction to theContractor.1.2.1.3.PROJECT REPRESENTATION BEYOND BASIC SERVICES1.2.1.The State may at its option secure the services of a person or persons known as a Clerk-of-the-Works, referredto herein as a "Clerk". The Clerk(s) shall, for all purposes of this Agreement, report and be solely responsibleto the State. The State may at any time dismiss the Clerk(s) for cause or convenience; however, any suchaction shall not affect the State's and ARCHITECT/ENGINEER'S obligations under this Agreement. In suchevent, the State shall use their best efforts to secure the services of a Clerk or Clerks under this paragraph assoon as is practicable if the State deems it necessary.1.2.2.The Clerk(s) shall make continuous and complete on-site inspections of the work performed on the Project, tothe extent reasonable under all circumstances. The on-site inspections of the work performed, and anyreports prepared by the Clerk(s) will be made available to the ARCHITECT/ENGINEER for use in making his/herDetermination and Report under this Agreement; however, the use of the Clerk’s on-site inspections orreports does not relieve the ARCHITECT/ENGINEER from his/her obligations under Paragraph 1.1.9.6. of thisAgreement and it is solely the responsibility of the ARCHITECT/ENGINEER to ensure that the work hasprogressed to the point indicated and that the quality of the work is in accordance with the ContractDocuments. Further, through such on site observations by the Clerk(s), the ARCHITECT/ENGINEER shallendeavor to provide protection for the State against defects in the Work, but the furnishing of such Clerk(s)shall not: (1) make the ARCHITECT/ENGINEER responsible for the Contractor's failure to perform the Work inaccordance with the Contract Documents; or (2) Relieve the ARCHITECT/ENGINEER from his/her obligation toexercise due diligence and ensure that the work has progressed to the point indicated and that the quality ofthe work is in accordance with the Contract Documents.ADDITIONAL SERVICES1.3.1.The following services are not covered in Paragraphs 1.1.4 through 1.1.9 If any of these Additional Services areauthorized in writing by the State, they shall be provided by the ARCHITECT/ENGINEER and paid for by theState as hereinbefore provided.1.3.2. Providing special analyses of the State's needs, programming the requirements of the Project and assistanceApril 22, 2018Page 6 of 16
CONTRACT 36514to the permitting process, except as otherwise herein provided.1.3.3.Providing financial feasibility or other special studies.1.3.4.Providing planning surveys, site evaluations, or comparative studies of prospective sites.1.3.5.Revising previously approved Drawings, Specifications or other documents to accomplish changes not initiatedby the ARCHITECT/ENGINEER, except as provided in Paragraphs 1.1.9.14 and 3.5.1.3.6.Providing the required services to execute all State-initiated Change Orders.1.3.7.Preparing documents for alternate bids requested by the State.1.3.8.Providing Detailed Estimates of Construction Costs, except as otherwise herein provided.1.3.9.Providing consultation concerning replacement of any work damaged by fire or other cause duringconstruction and furnishing professional services of the type set forth in Paragraphs 1.1 through 1.8 as may berequired in connection with the replacement of such work.1.3.10. Providing professional services made necessary by the default of the Contractor in the performance of theConstruction Contract.1.3.11. Providing Contract administration and observation of construction after the Contract Time has been exceededby more than sixty (60) days through no fault of the ARCHITECT/ENGINEER.1.3.12. Providing services not caused by errors, inconsistency or an omission of the ARCHITECT/ENGINEER after finalpayment to the Contractor.1.3.13. Providing the services required for or in connection with the selection of furniture and furnishings.1.3.14. Providing services for planning tenant or rental spaces.1.3.15. Making measured drawings of existing construction when required for planning additions or alterationsthereto, except as otherwise herein provided.1.3.16. Other services as may be required such as: LEED ratings, energy modeling, commissioning beyond thatrequired by 1.1.9.12, audio visual design, floodway studies, laser scanning of buildings, and geotechnicalinvestigations.ARTICLE 2 - THE STATE'S RESPONSIBILITIES2.1.The State shall provide full information regarding its requirements as identified in the SOW RFP.2.1.1.The State shall designate a representative authorized to act in its behalf with respect to the Project. The Stateor its representative shall examine documents submitted by the ARCHITECT/ENGINEER and shall renderdecisions pertaining thereto promptly, to avoid unreasonable delay in the progress of theARCHITECT/ENGINEER'S work.2.2.The State shall furnish structural, mechanical, chemical and other laboratory tests, inspections and reports as requiredby law or t
th, 2018,Contract # 36514, as amended to date(the "Contract"), is hereby amended as follows: I. Contract Term. The Contract end date, wherever such reference appears in the Contract, shall be changed from 06/18/2021 to 06/18/2022. II. Attachment A, Scope of Services. The scope of services is amended to include the following:
